Standard One Year Limited Warranty — One Year Parts

Standard One Year Limited Warranty — One Year Parts
Standard One Year Limited Warranty — One Year Parts, 90 Day Labor
The Delfield Company (“Delfield”) warrants to the Original Purchaser
of the Delfield product (herein called the “Unit”) that such Unit, and all
parts thereof, will be free from defects in material and workmanship
under normal use and service for a period of one (1) year from the date
of shipment of the Unit to the Original Purchaser or one (1) year from
the date of installation if registration is completed one (1) year from
installation. During this one year warranty period, Delfield will repair
or replace any defective part or portion there of returned to Delfield by
the Original Purchaser which Delfield determines was defective due to
faulty material or workmanship. Only during the first 90 days of the
this one year warranty period, Delfield will, subject to the limits set
forth below, pay labor, crating, and freight incurred in the removal of
the Unit of defective component and shipment to Delfield. A maximum
of 1-hour is allowed to diagnose a defective component. A maximum
of 1-hour is allowed for retrieval of parts not in stock. A maximum
travel distance of 100 miles round trip and 2-hours will be reimbursed.
Overtime, installation/start-up, normal control adjustments, general
maintenance, glass breakage, freight damage, delayed site entry
because of security or hours of operation and/or correcting an enduser installation error will not be reimbursed under warranty unless
pre-approved with a Service Work Authorization from Delfield. Delfield
will pay the return costs if the Unit or part thereof was defective.
The term “Original Purchaser” as used herein means that person, firm,
association, or corporation for whom the Unit was originally installed.
This warranty does not apply to any Unit or part thereof that has
been subjected to misuse, neglect, alteration, or accident, such
as accidental damage to the exterior finish, operated contrary to
the recommendations specified by Delfield; or repaired or altered
by anyone other than Delfield in any way so as to, in Delfield’s sole
judgment, affect its quality or efficiency. This warranty does not
apply to any Unit that has been moved from the location where it was
originally installed. This warranty also does not cover the refrigerator
drier, door gaskets or the light bulbs used in the Unit. The warranty
is subject to the user’s normal maintenance and care responsibility
as set forth in the Service and Installation Manual, such as cleaning
the condenser coil, and is in lieu of all other obligations of Delfield.
Delfield neither assumes, nor authorizes any other person to assume
for Delfield, any other liability in connection with Delfield’s products.
Removal or defacement of the original Serial Number or Model
Number from any Unit shall be deemed to release Delfield from all
obligations hereunder or any other obligations, express or implied.
Parts furnished by suppliers to Delfield are guaranteed by Delfield
only to the extent of the original manufacturer’s express warranty to
Delfield. Failure of the Original Purchaser to receive such manufacturers
warranty shall in no way create any warranty, expressed or implied, or
any other obligation or liability on Delfield’s part in respect thereof.
Under no condition does this warranty give the Original Purchaser the
right to replace the defective Unit with a complete Unit of the same
manufacturer or of another make. Unless authorized by Delfield in
writing, this warranty does not permit the replacement of any part,
including the motor-compressor, to be made with the part of another
make or manufacturer.
No claims can be made under this warranty for spoilage of any
products for any reason, including system failure.
The installation contractor shall be responsible for building access,
entrance and field conditions to insure sufficient clearance to allow
any hood(s), vent(s), or Unit(s) if necessary, to be brought into
the building. Delfield will not be responsible for structural changes
or damages incurred during installation of the Unit or any exhaust
system.
Delfield shall not be liable in any manner for any default or delay in
performance hereunder caused by or resulting from any contingency
beyond Delfield’s control, including, but not limited to, war,
governmental restrictions or restraints, strike, lockouts, injunctions,
fire, food, acts of nature, short or reduced supply of raw materials, or
discontinuance of the parts by the original part manufacturer.
Except as provided in any Additional Four Year Protection Plan, if
applicable, and the Service Labor Contract, if applicable, the preceding
paragraphs set forth the exclusive remedy for all claims based on
failure of, or defect for Delfield products sold hereunder, whether
the failure or defect arises before or during the warranty period, and
whether a claim, however instituted, is based on contract, indemnity,
warranty, tort (including negligence), strict liability, implied by statute,
common-law or otherwise , and Delfield and its agents shall not be
liable for any claims for personal injuries or consequential damages or
loss, howsoever caused. Upon the expiration of the warranty period,
all such liability shall terminate. THE FOREGOING WARRANTIES ARE
EXCLUSIVE AND IN LIEU OF ALL OTHER WARRANTIES, WHETHER
WRITTEN, ORAL, IMPLIED OR STATUTORY. NO IMPLIED WARRANTY
OF MERCHANTABILITY OR FITNESS FOR PARTICULAR PURPOSE
SHALL APPLY, DELFIELD DOES NOT WARRANT ANY PRODUCTS OR
SERVICES OF OTHERS
This warranty supersedes and excludes any prior oral or written
representations or warranties. The sole and exclusive remedies of
any person relating to the Unit, and the full liability of Delfield for any
breach of this warranty, will be as provided in this warranty.
Other than this Delfield Standard One Year Limited Warranty, any
applicable Delfield Additional Four Year Protection Plan or applicable
Delfield Service Labor Contract, the Original Purchaser agrees and
acknowledges that no other warranties are offered or provided in
connection with or for the Unit or any other part thereof. The liability
of Delfield for breach of any warranty obligation hereunder is limited
to: (i) the repair or replacement of the Delfield Product on which the
liability is based, or with respect to services, re-performance of the
services; or (ii) at Delfield’s option, the refund of the amount paid for
said equipment or services. Any breach by Delfield with respect to any
item or unit of equipment or services shall be deemed a breach with
respect to that item or unit or service only
IN NO EVENT WILL DELFIELD BE LIABLE FOR SPECIAL, INCIDENTAL
OR CONSEQUENTIAL DAMAGES, OR FOR DAMAGES IN THE NATURE
OF PENALTIES.
If shipment of a replacement part is requested prior to the arrival in
the Delfield factory of the part claimed to be defective, the Original
Purchaser must accept delivery of the replacement part on a C.O.D.
basis, with credit being issued after the part has been received and
inspected at Delfield’s plant and determined by Delfield to be within
this warranty.
For customer service, call +1 (989) 773-7981, www.delfield.com
Additional Four Year Protection Plan — For Motor-Compressor Only
Delfield Model# Serial# Installation Date
In addition to the Standard One Year Warranty on the MotorCompressor contained in the above listed Delfield product (the
“Unit”), The Delfield Company (“Delfield”) also agrees to repair, or
exchange with similar or interchangeable parts in design and capacity
at Delfield’s option, the defective Motor-Compressor contained in the
Unit (the “Motor-Compressor”), or any part thereof, for the Original
Purchaser only, at any time during the four (4) years following the
initial one (1) year period commencing on the date of installation for
the Original Purchaser. This additional Warranty is only available if the
Motor-Compressor is inoperative due to defects in material or factory
workmanship, as determined by Delfield in its sole judgment and
discretion. The Original Purchaser shall be responsible for returning
the defective Motor-Compressor to Delfield prepaid, F.O.B. at the
address shown on the back cover of this manual.
The term “Original Purchaser” as used herein shall be deemed to mean
that person, firm, association, or corporation for whom the equipment
was originally installed.
The term “Motor-Compressor” as used herein does not include unit
base, air or water-cooled condenser, receiver, electrical accessories
such as relay, capacitors, refrigerant controls, or condenser fan/motor
assembly. This warranty does not cover labor charges incidental
to the replacement of parts. This warranty further does not include
any equipment to which said condensing unit is connected, such as
cooling coils, temperature controls or refrigerant metering devices.
This warranty shall be void if the Motor-Compressor, in Delfield’s
sole judgment, has been subjected to misuse, neglect, alteration or
accident, operated contrary to the recommendations specified by the
Unit manufacturer, repaired or altered by anyone other than Delfield
in any way so as, in Delfield’s sole judgment, to affect its quality or
efficiency or if the serial number has been altered, defaced or removed.
This Warranty does not apply to a Motor-Compressor in any Unit that
has been moved from the location where it was originally installed.
The addition of methyl chloride to the condensing unit or refrigeration
system shall void this warranty.
General Conditions
Delfield shall not be liable in any manner for any default or delay in
performance thereunder caused by or resulting from any contingency
beyond Delfield’s control including, but not limited to, war,
governmental restrictions or restraints, strikes, lockouts, injunctions,
fire, floods, acts of nature, short or reduced supply of raw material
or discontinuance of any part or the Motor-Compressor by the unit
manufacturer.
Replacement of a defective Motor-Compressor is limited to one (1)
Motor-Compressor by us during the four (4) year period. Delfield shall
replace the Motor-Compressor part only at no charge.
This Warranty does not give the Original Purchaser of the MotorCompressor the right to purchase a complete re placement MotorCompressor of the same make or of another make. It further does
not permit the replacement to be made with a Motor-Compressor
of another kind unless authorized by Delfield. In the event Delfield
authorizes the Original Purchaser to purchase a replacement MotorCompressor locally, only the wholesale cost of the Motor-Compressor
is refundable.
Expressly excluded from this warranty are damages resulting from
spoilage of goods.
Except as provided in any applicable Standard One Year Limited
Warranty or applicable Service Labor Contract, the foregoing is exclusive
and in lieu of all other war ran ties, whether written or oral, express
or implied. This Warranty supersedes and excludes any prior oral or
written representations or warranties. Delfield expressly disclaims any
implied warranties of merchantability, fitness for a particular purpose
or compliance with any law, treaty, rule or regulation relating to the
discharge of substances into the environment. The sole and exclusive
remedies of any person relating to the Motor-Compressor, and the full
liability of Delfield for any breach of this Warranty, will be as provided
in this Warranty.
Other than any applicable Delfield Standard One Year Limited Warranty,
this Delfield Additional Four Year Protection Plan and any applicable
Delfield Service Labor Contract, the Original Purchaser agrees and
acknowledges that no other warranties are offered or provided in
connection with or for the Motor-Compressor or any part thereof. In
no event will Delfield be liable for special, incidental or consequential
damages, or for damages in the nature of penalties.
For customer service, call +1 (989) 773-7981, www.delfield.com
Was this manual useful for you? yes no
Thank you for your participation!

* Your assessment is very important for improving the work of artificial intelligence, which forms the content of this project

Download PDF

advertisement