(D.S.I.T.C) With Five years of Operation & Maintenance Contract of 2

(D.S.I.T.C) With Five years of Operation & Maintenance Contract of 2
TENDER DOCUMENT NO.
RCB/BSC/F.146 /SPV/2015-16/01
(Three Bid system)
NAME OF WORK:
DESIGN, SUPPLY, INSTALLATION, TESTING, COMMISSIONING (D.S.I.T.C)
WITH FIVE YEARS OF OPERATION & MAINTENANCE CONTRACT OF 2 x 25
kWp On line Grid Tied SOLAR PHOTOVOLTAIC POWER PLANTS AT NCR BIOTECH SCIENCE CLUSTER, GURGAON-FARIDABAD EXPRESSWAY,
VILLAGE BHANKRI, FARIDABAD-121004 (HARYANA).
CLIENT:
EXECUTIVE DIRECTOR, RCB FARIDABAD
FLOATING TENDER ON BEHALF OF RCB & THSTI
COST OF TENDER DOCUMENT: - Rs. 1,500/-
-1-
INDEX
Sl. No
Description
Page No.
1
Index
2
Tender notice
3-4
3
Detailed tender notice
6-10
2
I)
Eligibility criteria & Cover System
6
II)
Scope of the work
13
III)
Instructions to bidders
IV)
Procedure for opening the bids
V)
Bid Evaluation Criteria
20-21
VI)
General terms & conditions
22-28
16-18
VII) Technical specifications
19
29-38
4
Annexure – I: Details of earnest money deposit
34
5
Annexure – II: Tenderer’s general information
35
6
Annexure – III: Declaration
36
7
Annexure – IV: Company profile with staff details & Work experience
37
8
Annexure – V: Technical bid
40
9
Annexure –VI: Financial bid
42
10
Annexure –VII: Accredited Test centers
43
11
Check list
45
-2-
TENDER NOTICE
TENDER DOCUMENT NO. RCB/BSC/F.146 /SPV/2015-16/01 Dt. 09/04/2015
Sealed tenders are invited under three bid system (Pre Qualification, Technical &
Financial) from Manufacturers/ Suppliers of Solar PV Systems who must be channel
partners of MNRE in India having valid test certificates from MNRE authorized test centers
for their products for “Design, Supply, Installation, Testing and Commissioning of Two
numbers of each 25 kWp On Line Grid Tied Solar Photovoltaic Power Plants with
aggregated capacity of 50 kWp with Five Years of Operation & Maintenance Contract”
for RCB & THSTI buildings at NCR-Biotech Science Cluster, Gurgaon-Faridabad Expressway
Village- Bhankri, Faridabad (Haryana).
Period of issue of Tender Document :
13th April 2015 to 12th May 2015 during working
days and office hours only during 11.00 AM to
The
tender
document
can
be 16.00 PM.
downloaded from RCB/THSTI website
(www.rcb.res.in & www.thsti.res.in)
during sale period.
Cost of Tender Document :
Rs. 1500 /-(Rupees One thousand Five hundred
only) in the form of a demand draft/ pay order in
favour of “Executive Director, Regional Centre
for Biotechnology”, payable at Gurgaon, from
nationalized bank only.
Estimated Cost :
Rs. 50.28 Lacs.
Earnest Money Deposit :
Rs. 2.00 Lacs by D.D./ F.D. in favour of Executive
Director, Regional Center for Biotechnology
payable at Gurgaon from any Nationalized bank.
Security Deposit by the Successful 10% of total contract value by D.D/F.D in favour
Bidder
of “Executive Director, Regional Centre for
Biotechnology”, payable at Gurgaon, from
nationalized bank only.
Period of Completion :
Four months.
One Similar completed work contract
Rs. 40.00 Lacs
Two Similar completed work contract
Rs. 25.00 Lacs
Three Similar
contract
Turnover per Year
completed
work Rs. 21.00 Lacs
Min Rs. 10.00 Crore/ annum
-3-
Year of Experience
Min seven Years
Pre Bid meeting
22nd April 2015 at 2.30 PM
Last Date of Submission :
13th May 2015 by 2.30 PM
Date of Opening :
13th May 2015 at 3.00 PM
The Executive Director, Regional Centre for Biotechnology reserves the right to accept /
reject any or all the tenders without assigning any reason therefore.
Sr. Manager (A&F) RCB
-4-
(TO BE SUBMITTED ALONG WITH TECHNICAL BID)
TENDER DOCUMENT NO. RCB/BSC/F.146 /SPV/2015-16/01
UNDERTAKING
The Executive Director,
Regional center for Biotechnology,
NCR-Biotech Science Cluster,
3rd Milestone, (towards Gurgaon)
Gurgaon-Faridabad Expressway
Village- Bhankri, Faridabad-121001
Haryana.
We the undersigned (herein after called as Contractor/Vendors/Suppliers) hereby
offer to execute supply of items as per specification against which we have quoted our rates
and for which this tender may be accepted at the rates stated there in and subject to the
terms & conditions set forth for such items as may be ordered by the Executive Director,
RCB or officer acting on his behalf.
Date this _____________ Day of______________
Signature of Contractor ______________________
Address __________________________________
________________________________________
________________________________________
Seal of the Tenderer__________________________________
-5-
DETAILED TENDER NOTICE
NAME OF WORK:
“Design, Supply, Installation, Testing and Commissioning of Two
numbers of each 25 kWp On-Line Grid Tied Solar Photovoltaic
Power Plants with aggregated capacity of 50 kWp with Five
Years of Operation & Maintenance Contract”
I. ELIGIBILITY CRITERIA & COVER SYSTEM
Cover-1 - Pre-Qualification (Before opening the Technical bid)
Cover-2 - Technical Bid
Cover-3 - Financial Bid
1.1 PRE QUALIFICATION: COVER – I:
1.
The Company should be Original Manufacturer of PV Modules with IEC 61215, 61730
1 & 2 certifications in India – proof to be submitted
2.
The Company should be a Channel Partner of MNRE (SPV) with a validity period of
2016 (or as per the norms of MNRE) – proof to be submitted
3.
The Channel partner should have allocation from the MNRE at least 250 kWp & above
for claiming the subsidy – proof to be submitted
4.
Channel partner’s company must be in business for the last 7 years (minimum) –
proof to be submitted
5.
The firm / sub contractor or technical agent has to produce valid Electrical A grade
license – proof to be submitted.
6.
The Company should be an ISO 9001 -2008 & 14001 2004 Certified – proof to be
submitted
7.
The firm, who has set up at least Two solar power plant of minimum 25 kWp or
above capacity in the premises of reputed Government building and State or Central
Universities and such other government buildings of national importance is preferred
– proof to be submitted
-6-
Important:
The firms who only qualify all the pre qualification criteria will be considered for
further evaluation.
Hence the tenderer should ensure before quoting that they qualify the pre bid criteria.
1.2 TECHNICAL BID: COVER-2:
EMD should be put in separate envelope with EMD super subscribed over it and
should be put in envelope cover-II. Tenders received without requite EMD will
be out right rejected and Technical bid will not be opened in that case.
1.
The channel Partner should have installed / commissioned at least 2 X 25 kWp
On-line Grid Solar PV Power Plant in India which are in useful operation before
tender due date – proof to be submitted
2.
The
Channel
partner
should
have
installed/commissioned
and
maintenance/after sale services in the field of Off-Grid Solar PV systems of more
than 1 Mw cumulative capacities in India before tender due date – proof to be
submitted
3.
The Annual turnover of the Company in the last financial year should be at least
Rs 10 Crore from similar works (Group of Companies turnover not
acceptable) – proof to be submitted
4.
Net worth of company should be at least One crore – proof to be submitted
6.
The bidder should produce valid PAN, TIN & TAN, VAT clearance Certificate
and latest copy of IT Returns (FY 11-12, FY 12-13, FY 13-14) – proof to be
submitted
7.
The proof of documents should be attested by Gazetted officer/Notary.
8.
The Tenderer should have at least;
a)
One similar completed work contract of Rs.40.0 lacs or more;
OR
b)
Two similar completed work contracts of Rs.25.0 lacs or more;
OR
c)
Three similar completed work contracts of Rs. 21.0 lacs or more.
The bidder will be required to make a short presentation on the scheduled date
to the expert committee on the salient features of its product and methodology
for providing the product with in stipulated time frame and its up keep post sales
to NCR Biotech Science Cluster, Village Bhankri, Faridabad -121004 (Haryana).
-7-
1.3 FINANCIAL BID: COVER-3:
1.
Sealed envelope (Cover -3) should contain Price bid as per Annexure –VI in a
separate sealed envelope. It should be super-scribed with "ENVELOPE-3 PRICE
BID". Any condition in regard to financial aspects, payments, terms of rebate etc
beyond the prescribed financial terms of RCB will make the bid invalid.
Therefore it is in the interest of the bidders not to write anything extra in the
Price Bid in Annexure-VI except price. The tenders may enclose the detailed
item-wise, work-wise break-up with the price bid. However, the bids will be
evaluated on the basis of consolidated price bid as per ANNEXURE-VI.
2.
Price bid should include a separate section on details of post warranty period
AMC charges and details of terms and conditions for CMC and warranty.
3.
B
Price bid should include all Taxes as may be applicable.
Following documents are required to be sent to the address mentioned in the stipulated
time. The bid criteria as mentioned in table must be fulfilled and supported by relevant
document as indicated below.
No.
Eligibility Bid Criteria
Document
1
Annexure I
Properly filled and duly signed and stamped.
2
Bid
Security
(EMD)
of DD/Pay Order/Banker’s Cheque /Bank guarantee in
Rs. 2,00,000.00 only
favour of “Executive Director, Regional Centre for
Biotechnology” payable at Gurgaon,
along with
properly filled, signed and stamped Annexure II
3
Annexure III
Copy of IT return and acknowledgment of the Income Tax
Department for the any three consecutive financial years,
2011-12, 2012-13,2013-14 and photocopy of PAN card
Annexure III
4
Undertaking
by
Bidder/ On official letter head of Bidder/ Agency, duly signed and
Agency as mentioned in
stamped by Bidder/ Agency.
Annexure IV
5
Undertaking
by
Bidder/ As explained above.
Agency as mentioned in
Annexure V
6
Financial Standing Solvency Signed certificate from Bank manager/authorized official
Certificate of Rs. 1.0 crore or
more from a scheduled bank
7
List of Major Clients
List of at least three major clients with annual contract
-8-
value for not less than Rupees 21.00 Lacs P.A in each
Organization.
8
License under
Only those who hold valid registration with the Labour
Department , electrical, other departments required, for
carrying out such works, valid in Haryana shall be eligible
to bid in response to NIT and if found successful the
workmen shall need to get registered with the labour
department. Photocopy of license duly signed and
stamped by Bidder/ Agency
9
Experience
similar
of
providing A certificate from the authorized official of the concerned
Services in at least organization.
two Government organization
(Annexure -IV)
10
Validity period
The Tender shall remain valid for the period of six
months from the date of submission of Tender
document
C.
Even though the applicants meet the above criteria, they are subject to be disqualified if
they have:
i)
Made misleading or false representation in the form, statement and attachments
submitted in and or
ii)
Record of poor performance such as abandoning the work, not properly
completing the contract, inordinate delays in completion, litigation history, or
financial failures, etc.
iii)
2.
Found to have been black listed in any other works.
GENERAL
1.
Regional Center for Biotechnology (RCB), under the Department of
Biotechnology, Ministry of Science & Technology, Govt. of India is setting up its
new campus at NCR Biotech Science Cluster Faridabad with the State-of-Art
Research & Development facilities.
2.
The Centre has an existing contract demand of 4000 KVA, 11 KV electric supply
from DHBVNL, Faridabad. The 11 KV supply is stepped down to 415 volts using
transformers. The power is distributed through Power Control Centre/Motor
Control Centre to cater to lighting, Air conditioning loads of the building. The
-9-
electric supply is backed up by Two 1500 Kva Captive Diesel Generating Sets to
meet the power backup requirement.
3.
RCB intends to install a Solar Photovoltaic Power Generating System capable of
integration with the existing 11 KV supply from DHVBNL. The available space
on the terrace of each of Two buildings is proposed to house the 2 x 25Kwp
Solar Photovoltaic panel and their structures and the required integrating panels
will be housed in a suitsble place in the buildings which will be jointly identified
by the supplier along with the client.
The scope of work included in this tender includes the design, engineering,
manufacture, supply, installation, testing and commissioning of a Solar
Power Generating system capable of supplying 2x 25 KWp power with Five
Years of Operation & Maintenance. All required works for the execution and
integration of the system with the existing system are in the scope of work
included in this tender including designing and providing protection Guard.
4.
The job to be executed is to be of best quality and conforming to all relevant
national and international standards.
5.
The competent parties are advised to visit the site and acquaint themselves with
the area where the job included in this tender is to be executed.
3.0
INTRODUCTION
RCB & THSTI proposes to set up a 2 X 25.0 Kwp grid connect Solar Photovoltaic power
plant
with protective guards at their New Campus buildings at village Bhankri,
Faridabad with the objective of power generation from Solar Photovoltaics
Typical Bill of Materials per 25.0 Kwp Power Plant shall consist of:
•
Solar Array capacity
:
25.0 kWp
•
Solar Modules Mounting Structure
:
1 Set
•
Power Conditioning Unit – 25 kVA
:
1 Nos
•
Data Logging System
:
1 No
•
Junction Boxes
:
1 Set
•
Cables & Earthing materials
:
1 Set
•
Distribution Panels
:
1 set
Others Requirements:
•
Control Room
•
Installation and commissioning
•
Operation and Maintenance.( for five years)
- 10 -
•
Protective Guard (design , fabrication and errection) using 2” x 3”of 4mm wire
mesh with 1.5” MS angle frame. The design of the same will be got approved
from the Engineer in-charge (Project)
3.1
The OBJECTIVE
Main Objective of setting up the power plant is to support peak electrical load during day
time. The solar power plant shall operate on the principle of direct conversion of sunlight
to electrical energy by employing photovoltaic technology.
3.2
BENEFITS
The solar photovoltaic system should provide the following benefits:
I.
VOLTAGE SUPPORT
The PV system will reduce the power drawn from grid and prevent the voltage drop
which is generally experienced at the time of switching on of large inductive loads.
The system shall also supply power close to unity power factor there by improving
the grid quality and increasing its capacity.
II.
SOCIAL BENEFITS
By realization of the untapped Solar energy, carbon dioxide and other
toxic
gas
emission can be lowered by significant quantity and there by saving our
environment through mitigation of carbon emission and subsequently combat
climate change.
3.3
Note:
LOCATION OF SITE
Location
:
Site Access
:
New campus of RCB/THSTI in NCR- Biotech Science
Cluster, 3rd Milestone (towards Gurgaon) Vill- Bhankri,
Gurgaon-Faridabad Expressway, Faridabad (Haryana).
By Road
Latitude &
Longitude
:
28.39 Latitude & 77.27 Longitude
The height of support structures shall be such that the there shall be sufficient clearance
for solar PV array to remain shadow free, prevent shadow of front structures to fall onto
the one installed behind. The row space would also allow easy access to array for
cleaning and repair.
3.3.1 Solar Insolation level / Temperature
Modules alignment and tilt angle shall have to be calculated to provide the maximum
annual energy output. Average solar insolation (Daily mean Global Horizontal) and
ambient temperature (Maximum averaged over month) at site may be assumed to be:
- 11 -
Month
Average Ambient
Temperature deg C
22.40
24.30
24.90
26.90
28.70
29.90
29.10
27.50
27.10
27.40
28.30
27.50
Jan
Feb
Mar
Apr
May
Jun
Jul
Aug
Sep
Oct
Nov
Dec
Horiz. Radiation
kWh/m2/day
3.63
4.67
5.88
6.73
7.02
6.58
5.83
5.46
5.30
5.30
4.34
3.56
Note: Average solar radiation for Faridabad (28.39 N 77.27 E) has been mentioned
above. Depending on the actual site location, modules alignment and tilt angle
shall have
to be calculated to provide the maximum annual energy output.
3.4.0 SCOPE OF WORK
The following section of the document describes the scope of work for 2x 25.0 Kwp
Grid connect Photovoltaic system at NCR- Biotech Science Cluster Buildings, Faridabad.
This job involves by means of enclosed specification “Design, Supply, Installation,
Test in g & Commissioning of the Solar PV Power Plant with Five years of
Operation & Maintenance.
The Scope of Work shall include the following,

Design, manufacture, supply of Solar PV Power Plant

Detailed planning of smooth execution of the project

Performance testing of the complete system

Warranty of the system for one-year faultless operation.

After sales service, directly or through local contractual arrangement

Risk liability of all personnel associated with implementation and
realization of the project

Training of at
least Four persons to be nominated by RCB /THSTI on the
various aspects of operation and maintenance of the offered systems.

The module layout as considered by the Bidder should be on the basis of clear
open shadow free available on the roof of the RCB/THSTI buildings

The Power Conditioning Unit (Central inverter), DCDB, Metering panel, Isolation
panel are housed inside the proposed control room to be housed in the
- 12 -
suitable place in the campus buildings.The requirement of conditioned air
(if any) for these units is to considered by the Bidder in terms of providing
suitable enclosures and air conditioning the same.

All cabling work (external & internal) inclidung connection with the existing
distrubution system in the building s & construction of control room ( including
drawing).

The tenderer is required to visit the site and quote as per actual site conditions.
Any additional works not covered above, but necessary for the functioning
of the system and required as per specification are to be incorporated. The
items of minor nature, which are not mentioned, shall be incorporated by
the Tenderer.
3.5.
SYSTEM DESCRIPTION
The Photovoltaic (PV) Grid connect system consists mainly of 3
components:
The PV array, Module Mounting Structure and the Power conditioning Unit
(PCU). The PV module converts sunlight to direct current (DC) power. The Module
mounting structure is used to hold the module in position. The DC power is
converted to alternating (AC) by the PCU and utilized for requirement within the
Building and excess power can be exported to utility power grid.
Fig: System Schematic
The multi crystalline solar modules used shall be grouped in an optimum number of
strings with module-to module cable connections. The modules shall be held
- 13 -
fixed on structures made of galvanized steel structures. The modules shall be
inclined at optimum horizontal tilt angle facing due south depending on the site
location. The DC output from the modules shall be fed to Array junction box and the
strings are to be paralleled at Sub Main & Main Junction Boxes. The output of the
main junction box shall be fed to DC distribution board (DCDB). The DC power
output from the DCDB is fed to the Power Conditioning Unit (PCU). The Powerconditioning unit shall be installed in a control room converts DC energy produced by
the solar array to AC energy.
The AC power output of the inverter shall be fed to the AC Distribution Board
(metering panel & isolation panel) which also houses energy meter. The 415V AC
output of the isolation panel is fed to the local bus bar it could be stepped up to the
required voltage level through power transformer and fed to the grid AC energy is
then synchronised with the grid and power is exported to the grid.
- 14 -
3.5.1 SYSTEM BILL OF MATERIALS
Major components of solar power plant shall consist of:

Multi crystalline solar modules

25 kVA Power Conditioning Units (Central Inverter)

Array /Sub main/Main Junction Boxes

Support Structures

AC Distribution Board (Metering panel, isolator panel) Bidder
shall
submit
details of make, Quantity, Relevant Standards, Technical Catalogues etc
complete for all the equipments included in its offer to meet the overall
technical and operational requirements of the system.
3.6.
CONTROL ROOM
The required control room shall be constructed at s ui table si te in campus and
necessary drawings for the same are to be submitted by the Bidder for the approval of
RCB/THSTI.
3.7.
SPARE PARTS
One set of essential spares for the system being offered shall be included in the offer and
details of the offered spares are to be included with the technical bid.
3.8.
DOCUMENTATION
Four sets of installation manual / user manual shall be supplied along with the each power
plant. The manual shall include complete system details such as array lay out,
schematic of the system, inverter details, working principle etc. Step by step maintenance
and trouble shooting procedures shall be given in the manuals.
- 15 -
Instruction to the Bidders
3.10
The Tenderer shall sign and put firm’s stamp on each page of the tender.
3.11
The original tender document shall be submitted with all Annexure as per procedure
for submission of tender on due date and time.
3.12
The conditional tenders will be rejected out rightly. Executive Director, RCB reserves
the right to reject/ accept any or all tender without assigning any reason thereof.
3.13
Period of completion of work is four months from the date of issue of work order.
3.14
Bidders must submit their bids for all items as stated above.
3.15
Bids must be submitted in English language only. Incomplete, telegraphic or
conditional bids shall not be accepted.
3.16
Prices quoted must be firm and fixed. No price variation / escalation shall be allowed.
3.17
The bidders must sign at the bottom of each page of the bid documents at the time of
submission in token of unconditional acceptance of the departmental terms and
conditions, technical specifications etc.
3.18
Valid TIN/VAT/Sales tax clearance certificate duly attested must be submitted along
with the bid.
3.19
Deviations in terms and conditions, Specification of material, Inspection clause etc. will
not be accepted under normal conditions.
3.20
EMD as specified in bid may be submitted in shape of Demand Draft drawn in favour of
the Executive Director, RCB payable at Gurgaon from any nationalized bank. Bids
without E.M.D will not be accepted.
3.21
The bidders are required to furnish their offers in the price bid both in words & figures.
In case of corrections ,if any, the original text/numerical must be clearly crossed out
and re-written legibly above, below or on the side of the crossed out characters as per
availability of space and the authorized person must put his dated initial under such
corrections. In case of any conflict between figures and words, the latter shall prevail.
3.22
Since timely execution of works is of paramount importance, requests for extension of
time shall not be ordinarily entertained.
3.23
Canvassing in any manner shall not be entertained and will be viewed seriously
leading to rejection of the bid.
- 16 -
3.24
Certificate to the effect that the systems to be supplied are indigenous & not fully
imported must be furnished.
3.25
Power of attorney to sign the agreement on behalf of bidders, if any, should be
enclosed along with original bid documents.
3.26
Notice inviting tender, bid documents, prescribed technical bid, price bid, terms &
conditions will form the part of the tender.
3.27
All pages of the bid documents must be signed & sealed by the authorized person on
behalf of the bidders.
3.28
Bids will be accepted & will be opened as per information mentioned in the noticeinviting tender. No receipt against submission of bid shall be issued by RCB.
3.29
Sealed tenders may only be dropped in the specified tender box kept in the office of
The Senior Manager, RCB Faridabad. Bids received after due date & time will not be
considered. The bids of such firms shall only be considered who have purchased the
bid documents from the RCB by depositing the prescribed fee of the bid document
(Non refundable) / downloaded from the website and submitted along with cost of the
tender document.
3.30
The bid document should be submitted in three parts as detailed below:
3.31
Bids should be submitted in three separate sealed envelopes addressed to the Senior
Manager, RCB Faridabad in a sealed envelope super scribed as “Bid for Solar PV
systems against DOCUMENT NO. “RCB/BSC/F.146 /SPV/2015-16/01”. First sealed
envelope should contain documents of Pre – qualifications as per qualification criteria
specified in para 1.1. It should be super-scribed with COVER -1, PRE QUALIFICATION.
Second sealed envelope should contain documents of certificate and proof as per
qualification criteria specified in para 1.2. In addition it should contain details of
Earnest Money Deposit with DD, Tenderers general information, declaration, company
profile with staff details & work experience, Technical bid in prescribed format as per
Annexure – I, II, III, IV and V. Also submit VAT certificate, VAT clearance certificate,
latest copy of IT returns, Indignity Certificate, balance sheets and profit & loss accounts
for last three years, prescribed test certificates as well as brochure, literature etc and
any other bid documents duly signed & sealed. It should be super-scribed with
- 17 -
COVER -2, TECHNICAL BID. All the papers of bid documents except documents of Pre
– qualifications and price bid duly signed should be submitted in the second envelope.
Required earnest money deposit in the form of Demand Draft in favour of Executive
Director, RCB payable at Gurgaon must be attached. If the bid document has been
downloaded from the website, the bank draft towards cost of bid document should be
submitted in a separate envelop super-scribed “cost of bid document” and kept in the
main envelop.
Third sealed envelope (COVER-3) should contain Price bid as per Annexure –VI in a
separate sealed envelope. It should be super-scribed with "COVER-3 FINANCIAL BID".
Any condition in regard to financial aspects, payments, terms of rebate etc beyond the
prescribed financial terms of RCB will make the bid invalid. Therefore it is in the
interest of the bidders not to write anything extra in the Price Bid in Annexure- VI
except price. The tenders may enclose the detailed item-wise, work-wise break-up
(including battery backup time separately) with the price bid. However, the bids will
be evaluated on the basis of consolidated price bid as per ANNEXURE -VI. Price bid
should include a separate section on details of post warranty period Operation &
maintenance charges and details of terms and conditions for CMC and warranty. Price
bid should include all Taxes as may be applicable.
- 18 -
IV. PROCEDURE FOR OPENING THE BIDS
The procedure of opening of the bid shall be as under
4.1
First envelope, COVER-1 “PRE-QUALIFICATION” shall be opened at the time & date
informed by RCB. Only qualified bidders from the pre-qualification criteria are eligible
for opening COVER-2 “TECHNICAL BID” and “COVER-3 PRICE BID.” The date for
opening of second and third envelopes shall be communicated subsequently.
4.2
Second envelope, COVER-2 “TECHNICAL BID” shall be opened at the time & date
informed by RCB in the presence representative of bidders, who choose to be present.
Only qualified bidders from the technical bid are eligible for opening “COVER-3 PRICE
BID”. Third envelope, “COVER-3 PRICE BID” containing Price bid shall be opened after
evaluation of technical suitability of the offer. Third envelope of only those bidders
shall be opened who qualify in the technical bid. If necessary, the firms may be called
for Technical Presentation of their product as per the time & date informed by RCB.
4.3
Any clarification on the technical specification and commercial terms and conditions
may be clarified in writing from RCB.
4.4
Deviation of any commercial terms and condition and technical specification shall not
be entertained under any circumstances.
4.5
Bidders may in their own interest visit the sites and undertake site visit before
submitting bids. RCB will not be responsible for any incidental or consequential losses
of the firms while execution and till expiry of the period of maintenance.
4.6
The supplied materials should strictly comply with the specifications as mentioned in
the bid; otherwise the material would be liable for rejection.
4.7
In case of supply of any defective material or substandard material, the materials will
be rejected & it is the responsibility of the tenderer for taking back & replacing the
rejected materials at their own cost. In case of non-lifting of such rejected materials
within a reasonable time offered by the office it will have the right to suitably disposeoff the same and forfeit the amount.
4.8
During the warranty period, MNRE/ State Agencies/ Users reserve the right to cross
check the performance of the systems with the minimum performance levels as
specified in the MNRE specifications.
- 19 -
V. BID EVALUATION CRITERIA
A. The bids shall be ranked on the basis of combined weighted score for quality and cost.
The tender shall be awarded to the bidder obtaining the highest total combined score
in evaluation of Technical bid and Price (financial) bid.
B. The bids shall be ranked keeping in view the marks obtained on a scale of 100 marks
during evaluation of bids. The technical and Price (financial) bids shall enjoy weight
age in the proportion of 60:40 i.e. 60% for the technical bid and 40% for the financial
bid.
The financial bids of only those successful bidders who obtain minimum 70% point i.e.
70/100 in Technical evaluation will be opened for financial evaluation.
C. Combined scores of respective bidders shall be obtained by sum of their respective
technical bid scores (out of 60) and their respective Price (financial) bid scores (out of
40).
D. (i) Criteria for evaluation of the technical bid/performance of contractors for preeligibility
Attributes
Evaluation
1.
Financial strength
(i) Average annual (last three years)
turnover 10 Crore/year
15 marks
(ii) Solvency Certificate 100 lacs
05 marks
2.
i
Experience in similar class of work
One similar works contract of Rs. 40 lacs or more
or
Two similar works contract of Rs. 25 lacs or more
or
Three similar works contract of Rs. 21 lacs or more
(20 marks)
(i) 60% marks for minimum
eligibility criteria
(ii) 100% marks for twice the
minimum eligibility criteria or more
In between (i) & (ii) – on pro-rata
basis for similar works.
(20 marks)
(i) 60% marks for minimum
eligibility criteria of works
(ii) 100% marks for twice the
minimum eligibility criteria or more
In between (i) & (ii) – on pro-rata
basis
For similar works
(10 marks)
(i) 60% marks for minimum
eligibility criteria of works
(ii) 100% marks for twice or more
the eligibility
(iii) In between pro-rata
(05 marks)
For certification 5 points
Otherwise Zero(0)
ii
iii
3.
Performance on timely attending completion.
Please attach completion certificate of
timely/satisfactory minimum two clients.
One of whom should be PSU/Govt. organization.
4.
ISO/ other certification of the firm
5.
Channel partner to have done Design, Supply,
Installation, Testing and Commissioning with
maintenance of on-line Grid Tied SOLAR
PHOTOVOLTAIC POWER system with minimum
- 20 -
(20 marks)
(i) 60% marks for minimum
eligibility criteria of works
(ii) 100% marks for twice or more
cumulative capacity of 1 Mw
6
Local office/service center in NCR with minimum
two Service Engineer.
7.
Performance of works (Quality) Based on
report/visit/ presentation
(i) Very Good
(ii) Good
(iii) Fair
(iv) Poor
Total
=
the eligibility
(iii) In between pro-rata
(10 marks)
(i) 60% marks for minimum
eligibility criteria of works
(ii) 100% marks for twice or more
the eligibility
(iii) In between pro-rata
Nil if min criteria is not met.
(15 marks)
15
10
05
0
100 marks
D. (ii) Financial bid evaluation:- The bidder quoting to lowest rate will be awarded full
points out of 40. Other will be awarded pro-rata.
5.1
The bid of any bidder who has not complied with one or more of the conditions will be
summarily rejected.
5.2
Conditional bids will also be summarily rejected.
5.3
Subsequently, the technical bids will be evaluated by the expert technical committee of
the Institutes on the basis of technical bid and technical specifications. The authority
for the acceptance of the tender rests with the RCB. The tenders received will be
evaluated by RCB Committee to ascertain the best acceptable tender in the interest of
RCB.
5.4
Financial bids of only the pre-qualification and technically qualified bidders will be
opened for evaluation in the presence of qualified bidders.
However, RCB shall not be bound to accept the lowest or any other tender or to assign
any reason for non-acceptance or rejection of a tender. RCB reserves the right to accept
any tender in respect of the whole or any portion of the work specified in the tender
paper
- 21 -
VI. GENERAL TERMS & CONDITIONS
6.1
RATE:
The offer should indicate the unit cost of the system, Installation & Commissioning
charges, AMC Charges and taxes & duties separately. The unit cost must be inclusive of
packing, forwarding, loading & unloading charges, cost of insurance and transportation
to the destination where the system will be installed as per the work order.
6.2
SALES TAX & DUTIES ETC.:
All Taxes and duties as prescribed both under Central and State Government sales tax
rules would be applicable.
6.3
EARNEST MONEY DEPOSIT:
6.3.1
Earnest money deposit as specified in Tender Notice is required to be deposited along
with the bid without which the bid will not be accepted. No interest will be payable for
the EMD amount under any circumstances.
6.3.2
Earnest money can be deposited in shape of a Demand Draft in favour of “Executive
Director, Regional Center Biotechnology”, from any Nationalized Bank Payable at
Gurgaon and the proof of deposits should be attached to the bid.
6.3.3
E.M.D would be refunded to the unsuccessful Bidders after finalization of the bid
without any interest.
6.3.4
The tenderer shall furnish balance E.M.D of 2% of the total contract value( Rs One lac
in this case) at the time of i.e date of issue of work order / agreement by way of
demand draft drawn in nationalized bank in favour of Executive Director ,Regional
Centre for Biotechnology
6.3.5
E. M. D would be forfeited in case of non- compliance of the purchase order by the
successful bidder.
6.4
SECURITY DEPOSIT (SD)/ PERFORMANCE GUARANTEE FEES:
6.4.1
S.D of 5 % of the total contract value of the bill shall be deducted at the time of final
settlement of the bill.
6.4.2
Failure to comply with the terms of security deposit shall result into cancellation of
work order without any further reference to the tenderer and the EMD shall be
forfeited.
6.4.3
The security deposit shall be liable to be forfeited wholly or partly at the sole
discretion of the RCB, if the tenderer either fails to execute the work of above projects
or fails to fulfill the contractual obligations or fails to settle in full his dues to the RCB.
- 22 -
6.4.4
In case of premature termination of the contract, the SD will be forfeited and the RCB
will be at liberty to recover the loss suffered by it & if additional cost is to be paid, the
same shall be recovered from the tenderer.
6.4.5
The RCB is empowered to recover from the SD for any sum due and for any other sum
that may be fixed by the RCB as being the amount or loss or losses or damages suffered
by it due to delay in performance and / or non-performance and / or partial
performance of any of the conditions of the contract and / or non-performance of
guarantee obligations.
6.4.6
The security deposit shall be released to the tenderer only after contract is completed
to the satisfaction of the RCB.
6.5
PROGRAMME EXECUTION SCHEDULE:
The submission of plan along with drgs and scheme of the system with in 15 days
of issue of W.O
6.5.1
Delivery of systems at sites: 2 months from the date of handing over the site to the
vendor for the purpose of erection of the PV power plant.
6.5.2
Installation & Commissioning: 2 months from the date of preliminary and performance
guarantee inspection, physical verification and test handing over of systems for
installation.
(The above dates are extendable by another one month under exceptional
circumstances.)
6.5.3
Upon intimation about commissioning of the systems by the executing firm a joint
inspection will be carried out by the representatives of the executing firm, RCB and
other officers from the Energy department, works Department etc.
6.5.4
The issuance of a JCC shall, in no way relieve the executing firm of its responsibility for
satisfactory operation of the power plant.
6.6
VALIDITY OF OFFER:
The offer must be kept valid for a period of six months from the date of opening of the
technical bid. No escalation clause except the admissible tax component under the period of
consideration would be accepted. The validity can be further extended with mutual consent as
per merit of the case.
- 23 -
6.7
WARRANTY:
The complete system should be warranted against any manufacturing defect or bad
workmanship at least for a period of 5 (five) years from the date of commissioning of the
systems.
Major system subcomponent SPV modules must be warranted against any manufacturing
defect of bad workmanship for a period of 20 years.
Warranty certificate to the above effect must be furnished along with the commissioning
reports.
Any defect noticed during warranty period should be rectified/replaced by the supplier with
free of cost upon due intimation by RCB.
Bidder shall without prejudice to any other clauses of the order repair/replace the defective
parts and restore the system to satisfactory working /performance within three days of
intimation of fault without any additional cost to the department within the period of CMC.
CMC will be valid for five years from the date of satisfactory installation /commissioning/
operation of the plants.
In case the supplier fails to rectify / replace the defective / damage equipment including
transit damages, shortage within 7 days from the date of intimation of such shortage /
damages, they shall have to pay penalty to the Department/ beneficiary as per details given in
break down/corrective maintenance.
The maintenance service provided shall ensure proper functioning of the system as a whole.
All preventive/routine maintenance and breakdown/corrective maintenance required for
ensuring maximum uptime shall have to be provided by the Bidder. Accordingly, this shall
have two distinct components as described below.
This shall be done by the company at least once in every three months and shall include
activities such as, cleaning and checking the health of the SPV system, cleaning of module
surface, tightening of all electrical connections, changing of tilt angle of module mounting
structure and any other activity that may be required for proper functioning of the SPV system
as a whole.
Breakdown/Corrective Maintenance
Whenever a complaint is lodged by the user, the bidder shall attend to the same within a
reasonable period of time (03 days) and in any case the breakdown shall be corrected within a
period not exceeding seven days from the date of complaint. If more than 07 days are taken
after registering of complaint, then Bidder has to pay Rs. 1000/- for each system for each day
till the problem is rectified subject to a maximum of the cost of the System This money shall be
deposited to the account of Executive Director, RCB.
- 24 -
For carrying out the maintenance effectively, before placing the firm supply order, the Bidder
shall have to establish at least one Office cum Service Centre in the name of the firm for
each division of the state wherein 1-2 local employees are to be appointed by the firm
depending upon the quantum of work order. These offices are to be run by the firms and
not by the local dealers whose services could be used for district wise service centres. In case
of Public sector undertakings necessary arrangements are to be put in place for providing
proper service network.
The bidder shall maintain the following facilities at the local Service Centre for ensuring
highest level of services to the end user:
i)
Adequately trained manpower, specifically trained by the bidder for carrying
out the service activities.
ii)
Adequate spares for ensuring least down time of an individual system.
Bidder shall furnish details of infrastructure that are presently available for establishing of
Service Centers.
Training Programs, after Sales Service and Availability of Spare Parts:
The responsibility of organizing training program will rest on the successful bidder. The
training program will be organized in consultation with RCB/Consignee. The training program
will focus on operation and maintenance of SPGs. Printed CATALOUGES should be made
available in English by the Bidder regarding the operation and maintenance of their SPGs.
The Bidder shall depute authorized Service Engineer within 2 days from the date of the
intimation of fault, and establish sufficient inventory of spares in the District/State to provide
satisfactory and uninterrupted services during the warranty period.
GUARANTEED GENERATION:
The tenderer shall give a guaranteed generation of minimum 3 units (kWh) per kW per day
from SPV Power Plant during 300 sunny days in a year during Operation & maintenance
contract period. Otherwise, tenderer have to pay an amount of Rs.50/- per unit as
compensation for the number of units not supplied against the guaranteed generation. The
tenderer shall provide sealed & tested energy meter at consumption side of SPV Power Plant.
Tenderer should quote the guaranteed generation in the offer. Daily reports of installed
system duly certified by concerned authorized RCB officer such as Coordinator of the
Project/Concerned in charge of the project will be submitted by the tenderer.
6.8 PENALTY AND TERMINATION OF CONTRACT:
The systems shall be supplied, installed and commissioned within the scheduled time. If the
supplier fails to adhere to the schedule, RCB shall without prejudice to its other remedies
under the contract deduct from the contract price as liquidated damages a sum equivalent to
- 25 -
1% of the delivery price of the delayed goods or unperformed services for each week of delay
until actual delivery or installation/commissioning up to a maximum deduction of 10% of the
contract price for delayed goods or installation and commissioning. Once the maximum is
reached (i.e. 14 weeks of delay) RCB may consider termination of the contract and forfeit the
security deposit without prejudice to the other remedies of the contract.
However, Competent Authority, of Regional Centre of Biotechnology may at his own
discretion allow reasonable time extension upon written application of the supplying firm. If
the delay is considered intentional or due to negligence of the vendor time extension can be
allowed with imposition of penalty. If the delay is considered to be genuine time extension can
be allowed without imposition of penalty.
6.9 FORCE MAJEURE:
The supplier of the SPV system shall not be charged with liquidated damages nor shall his
security for performance be forfeited when failure of the supplier in making delivery is due to
any event beyond the control of the supplier and could not have been foreseen, prevented or
avoided by a prudent person. These include, but are not restricted to acts of God, acts of public
enemy, acts of Government, fires, floods, epidemics, strikes, freights, embargoes and unusually
severe weather.
6.10 INSPECTION:
6.10.1 Pre delivery inspection of solar PV modules and other major components will be
carried out by a team of designated officials of RCB, and any other department as may
be considered appropriate at the factory site of the vendor.
6.10.2 RCB has the right to have the tests carried out at its own cost by an independent
agency at any point of time.
6.10.3 Tenderer shall inform Regional Centre of Biotechnology in writing when any portion
of the work is ready for inspection giving sufficient notice to enable RCB to send
representative to inspect the same without affecting the further progress of the work.
The work shall not be considered in accordance with the terms of the contract until the
competent person from RCB certifies in writing to that effect.
6.10.4 Approval of material or workmanship or approval of part of the work during the
progress of execution shall not bind the RCB or in any way affect him even to reject the
work which is alleged to be completed and to suspend the issue of his certificate of
completion until such alternation and modifications or reconstruction have been
effected at your cost as shall enable him to certify that the work has been completed to
his satisfaction.
- 26 -
6.11 PAYMENT:
Payment will be released as follows:
1.
25% of the cost of material supplied will be released on raising the bills towards cost of
supplies only on receiving panels with accessories and PCU etc.
2.
85% of the tendered cost, minus payments released against item No.1 above will be
released after supply, installation & successful commissioning of the systems duly
certified by Tenderer, and RCB. This does not cover CMC charges.
3.
15% of the tendered cost shall be released on submission of one month successful
performance report of the system duly certified by RCB and submission of performance
bank guarantee of 10% of total project cost from any Nationalized Bank valid for period
of 5 years and one month.
4.
CMC charges will be paid in stage manner on raising the bills.
5.
Deduction : The TDS at the source will be deducted as per the Govt. rule and regulations.
 RCB will issue necessary certificates of TDS deduction
 ‘C’/ ‘D’ from will not issued by RCB.
6.12 EXECUTION:
Execution of work shall be carried out in an approved manner as outlined in the technical
specification or where not outlined, in accordance with relevant Indian Standard Specification,
to the reasonable satisfaction of the Authorized RCB Officer.
6.13 LIMITATION OF LIABILITY:
RCB, will, in no case be responsible for any accident fatal or non-fatal, caused to any worker or
outsider in course of transport or execution of work. All the expenditure including treatment
or compensation will be entirely borne by the Executants. The Executants shall also be
responsible for any claims of the workers including PF, Gratuity, ESI & other legal obligations
6.14 DISPUTE:
For adjudication of any dispute between RCB and the bidders arising in this case, reference
can be made to any Law courts under the jurisdiction of Delhi only. The Executive Director,
Regional Centre of Biotechnology reserves the right to accept or reject any or all bids
without assigning any reason thereof.
- 27 -
6.15 RISK PURCHASE CLAUSE:
In case the successful tenderer fails to execute the project as mentioned above RCB reserves
the right to procure the similar service from the alternative source at the risk, cost and
responsibility of the successful tenderer.
6.16 INDEMNITY:
Successful tenderer shall indemnity, protect and save RCB all claims, losses , costs damages,
expenses, action suits and other proceedings, resulting from infringement of any patent , trade
mark copy right etc or such other statutory infringements in respect of all the equipment/
software supplied by him .
CLARIFICATION OF OFFERS:
To assist in the scrutiny, evaluation and comparison of offers, the RCB may at its discretion,
ask some or all tenderer for clarification of their offer. The request for such clarification and
the response will necessarily be in writing. All prospective tenderer who have purchased the
document shall be intimated of any amendment in writing by e-mail/post /uploading on the
websites of RCB and they shall be binding on them.
I/we have carefully read & understood the above terms & conditions of the bid & agree
to abide by them.
Signature of Bidder with Seal
- 28 -
VII)
TECHNICAL SPECIFICATIONS
The general scope under this contract includes to design, manufacture, testing ,inspection,
packing and forwarding, transportation up to project site, loading & unloading, storage in safe
custody, erection, carrying out preliminary tests at site, commissioning, performance testing,
operation and maintenance for 5 years & handing over to the purchaser all the equipment
installed 25 kWp SPV Power plants at NCR-BSC, Faridabad.
7.1 System Details for one power generator for installation of 25 KW SPV Power plants
(2 two to be installed):
Sl. No.
1
2
3
4
5
6
7
8
9
10
11
13
Brief Description
PV modules for a total capacity of
25 kWp as per specifications.
SPV module mounting structure
suitable for accommodating 25
kWp capacity SPV modules
including foundation as per
specifications on the rooftops of
the various Departments.
PCUs 240 V, 25 kVA as per
specifications
Units
1 Set
Array Junction Boxes
Main Junction Boxes
Data Logging system with remote
monitoring as per specification
DC Distribution units as per
AC Distribution units as per
specifications
Cables requirement as per design
1 Set
1 Set
1 Set
1 Set
1 Set
1 Set
1 Set
Make
TATA/BHEL/CEL/Aditi/a
ny MNRE approved
CPWD specifications
PPS/OPS/
Power
Electronics or any reputed
MNRE approved
Tyco / Hensel/ spelberg
Tyco / Hensel/ spelberg
System
as
per
specifications
Siemens/ABB/Schnieder
Siemens/ABB/Schnieder
Electric/L&T/Havells/HPL
As Finolex/Polycab/Havells/
at HPL of reputed make as
full per IS standards
Mtrs
required
site for
plants
commissioning
Lightning arrester complete set as 1 Set
CPWD Specifications
per specification
Earthing complete set as per 1 Set
CPWD Specifications
specification
Spares, tools and plant for 5 years 1 Set
operation and maintenance
- 29 -
14
15
16
17
18
19
Fuses, Transfer switches, Printed
Circuit boards required for power
plant
Providing training to engineers
and site staff for operating
Maintenance and trouble shooting
skills
Operation and maintenance of the
SPV Power Plant for a period of 5
years from date of commissioning
of the power plant.
Engineering, electrical drawings
and installations and O&M
manuals
Any other equipment required to
complete the installation
Lighting arresters
1 Set
Required
members
decided
RCB
I Item
as
by
1 Set
1 Set
1 Set
All the items against which no make has been mentioned must confirm to ISI standards.
7.2
Lightning protection:
There shall be the required number of suitable lightning arrestors installed in the array
field. Lightning protection shall be provided by the use of metal oxide resistors and
suitable earthing such that induced transients find an alternate route to earth.
Protection shall meet the safety rules as per Indian Electricity Act
7.3
Earthing protection :
Each array structure of the PV yard should be grounded properly. In addition the
lighting arrester/masts should also be provided inside the array field.. Provision
should be kept for shorting and grounding of the PV array at the time of maintenance
work. All metal casing/shielding of the plant should be thoroughly grounded in
accordance with Indian electricity Act./IE Rules. Earth resistance should be tested in
presence of the representative of RCB after earthing by calibrated earth tester. PCU
ACDB & DCDB should be earthed properly.
7.4
Fire extinguishers:
The fire fighting system for the proposed power plant for fire protection shall be
consisting of:
 Portable fire extinguishers in the control room for fire caused by electrical short
circuits.
 Sand buckets in the control room
- 30 -
 The installation of Fire Extinguishers should confirm to TAC regulations and BIS
standards. The fire extinguishers shall be provided in the control room and PCUs as
well as on the roof top where the PV arrays have been installed.

7.5
MINIMAL TECHNICAL REQUIREMENTS / STANDARDS FOR SPV SYSTEMS / PLANTS TO
BE DEPLOYED DURING F.Y. 2013-14 UNDER THE PROGRAMMES OF MINISTRY OF
NEW AND RENEWABLE ENERGY:
7.5.1 PV MODULES:
 The PV modules must conform to the latest edition of any of the following IEC / equivalent
BIS Standards for PV module design qualification and type approval:
Crystalline Silicon Terrestrial PV Modules IEC 61215 / IS14286
Thin Film Terrestrial PV Modules IEC 61646 / Equivalent IS (Under Dev.)
Concentrator PV Modules & Assemblies IEC 62108
 In addition, the modules must conform to IEC 61730 Part 1- requirements for
construction & Part 2 - requirements for testing, for safety qualification or Equivalent
IS (Under Dev.)
 IDENTIFICATION AND TRACEABILITY
Each PV module must use a RF identification tag (RFID), which must contain the
following information:
Name of the manufacturer of PV Module
Name of the Manufacturer of Solar cells
Month and year of the manufacture (separately for solar cells and module)
Country of origin (separately for solar cells and module)
I-V curve for the module
Peak Wattage, Im, Vm and FF for the module
Unique Serial No and Model No of the module
Date and year of obtaining IEC PV module qualification certificate Name of the
test lab issuing IEC certificate
Other relevant information on traceability of solar cells and module as per ISO
9000 series.
RFID shall be mandatorily placed inside the module laminate.
 Validity:
The validity of the existing Certificates/Reports /procedure shall be for five years.
- 31 -
 Authorized testing laboratories/ centers :
PV modules must qualify (enclose test reports/ certificate from IEC/NABL accredited
laboratory) as per relevant IEC standard. Additionally the performance of PV modules
at STC conditions must be tested and approved by one of the IEC / NABL Accredited
Testing Laboratories including Solar Energy Centre. For small capacity PV modules up
to 50Wp capacity STC performance as above will be sufficient. However, qualification
certificate from IEC/NABL accredited laboratory as per relevant standard for any of
the higher wattage regular module should be accompanied with the STC report/
certificate.
 Details of Test Labs are given in Annexure -VII.
(Any other Test Lab that has set – up for testing and wants to get included may contact
Director, MNRE)
While applying for Testing, the Manufacturer has to give the following details:
- A copy of registration of the company particularly for the relevant product/
component/ PV system to be tested
- An adequate proof from the manufacturer, actually showing that they are
manufacturing product by way production, testing and other facilities
- Certification as per JNNSM standards for other bought out items used in the system
Without above proof test centers are advised not to accept the samples.
 Warranty:
PV modules used in solar power plants/ systems must be warranted for their output
peak watt capacity, which should not be less than 90% at the end of 12 years and 80%
at the end of 25 years.
7.5.2 Balance of system (BOS) items/ components:
 The BOS items / components of the SPV power plants/ systems deployed under the
Mission must conform to the latest edition of IEC/ Equivalent BIS Standards/ MNRE
specifications / as specified below:
BOS Item / System
Solar PV Lighting Systems:
Charge Controller/MPPT units
Applicable BIS /Equivalent IEC Standard
Or MNRE Specifications
Standard Description
Standard Number
Solar PV Home Lighting System As
per
MNRE
latest
Solar PV street Lighting System Specifications dated 09.09.2011
Solar PV Lantern
Environmental Testing
IEC 60068-2 (1,2,14,30)
/Equivalent BIS Std.
- 32 -
Power conditioners / Inverters Efficiency Measurements
IEC 61683 / IS 61683
**
including
MPPT
and Environmental Testing
IEC 60068-2 (1, 2, 14, 30) /
Protections
Equivalent BIS Std.
Cables
General Test and Measuring IEC 60227 / IS 694
Method PVC insulated cables for IEC 60502 / IS 1554 (Pt. I & II)
working voltage up to and
including 1100 V and UV
resistant
for
outdoor
installation
Switches/Circuit Breakers
General Requirements
IEC 60947 part I,II, III /
/Connectors
Connectors –safety
IS 60947 Part I,II,III
A.C. /D.C.
EN 50521
Junction Boxes /Enclosures
General Requirements
IP 54(for outdoor)/ IP 21(for
for Inverters/Charge
indoor) as per IEC 529
Controllers/Luminaries
**In case if the Charge controller is in-built in the inverter, no separate IEC 62093 test is
required and must additionally conform to the relevant national/international Electrical
Safety Standards wherever applicable
 Authorized testing laboratories/ centers :
Test certificates / reports for the BoS items/ components can be from any of the
NABL/ IEC Accredited Testing Laboratories or MNRE approved test centers.
 Warranty :
The mechanical structures, electrical works including power conditioners/inverters/
charge controllers/ maximum power point tracker units/distribution boards/digital
meters/ switchgear etc. and overall workmanship of the SPV power plants/ systems
must be warranted against any manufacturing/ design/ installation defects for a
minimum period of 5 years.
- 33 -
ANNEXURE – I
DETAILS OF EARNEST MONEY DEPOSIT
(Separately typed on Tenderer Letter head is preferable & submitted in Envelope No.1)
TENDER DOCUMENT NO. RCB/BSC/F.146 /SPV/2015-16/01
Date:
To,
Executive Director
Regional center for Biotechnology,
180, Udyog Vihar Phase-I
Gurgaon-122016.
Subject: Earnest Money Deposit (EMD) for the Tender No: ______________________
Respected Sir,
I/We __________________________________________ (hereinafter referred to as the Tenderer)
being desirous of Biding for the work under the above mentioned Tender document
and having fully understood the nature of the work and having carefully noted all the
terms and conditions, specifications etc., as mentioned in the Tender document.
I/We feel an immense pleasure to quote our most competitive rates herewith duly
signed by me / us. I / We have quoted separately for the systems and the Earnest
Money Deposit/s has been submitted separately in Envelop 1
EMD details
Amount (Rs.)
: ___________________________________
Instrument Number : ___________________________________
Date of issuance
: ___________________________________
Name of the Bank
: ___________________________________
Place: (Signature of Tenderer)
Name :__________________________
Designation : _____________________
Date:
Seal :
- 34 -
ANNEXURE – II
TENDERER’S GENERAL INFORMATION
(To be typed separately & submitted in Envelope No.1)
To,
Executive Director
Regional center for Biotechnology,
Faridabad-121004
Subject : Tender No. RCB/BSC/F.146 /SPV/2015-16/01
1. Name of Tenderer
____________________________________________
2. Status of Firm
____________________________________________
3. Number of Years in Operation
____________________________________________
4. Registered Address
_____________________________________________
_____________________________________________
5. Operating Address
_____________________________________________
(If different from above.)
_____________________________________________
6. Telephone Number
_____________________________________________
[Area Code]
[Number]
7. E-mail Address & Web Site
_____________________________________________
8. Tele-fax Number
____________________________________________
[Area Code]
9. PAN [Number]
[Number]
________________________________
[Enclosed Copy of „PAN CARD‟]
10. Service Tax Number
_____________________________________________
[Enclosed copy of, Service Tax Registration Certificate]
(Signature of Tenderer)
Date
Name: ____________________________
Designation: _____________________
Place:
Seal:
- 35 -
ANNEXURE – III
DECLARATION
(To be submitted on Rs.100/- stamp paper)
I / We, hereby declare that I / We have made myself / ourselves thoroughly conversant
with the sub – soil conditions, local conditions regarding all materials and Labor of which I / we
have based my / our rates of this work. The specifications, conditions and lead of materials on this
work have been carefully studied and understood by me / us before submitting this Tender. I / We
undertake to use only the best materials defined / approved by the Ministry of New and
Renewable Energy (MNRE) GoI.
The systems will be provided as per the specifications and guidelines issued by the
Ministry of New and Renewable Energy / RCB. We are bound to adhere the guidelines issued by
the Ministry of New and Renewable Energy / RCB from time to time. We also hereby committed
that if in future MNRE make any changes in the specifications of the systems the same will be
incorporated in the present Tender projects. We hereby agree that the work will be executed
within the cost of Tender mentioned in the financial bid and there will be no escalation in cost for
any reason thereof. We also agree that if we fail to complete the work and drop the work in middle,
Regional Center for Biotechnology, Gurgaon shall have right to recover the full amount from us.
I / We shall accept any amendments made by RCB from time to time during total project
completion period including 5 years Operation & maintenance contract (CMC).
I / We am/are also committed that we shall complete the work within stipulated time
period specified in the work order for any work assigned by Order Issuing Organization. We will
not ask for any further time extension.
I / We am / are bound to work as per Tender and work Order issued by RCB for this work
with 5 years Operation & Maintenance Contract. In case of failure of the same, we shall be
responsible for any loss and for the action taken by competent Authority of RCB resulting to ban to
work and black-listing.
I / We shall comply with the provision of Contract Labour. (Regulation and Abolition) Act
1970, Minimum Wages Act. 1948, Payment of Wages Act. 1963, Workmen’s Compensation Act.
1961, the Contract Labour (Regulation and Abolition) Act, 1979 and all other related Acts and any
modification thereof or any law relating thereto and rules made there under from time to time.
RCB shall not be responsible in this regard.
I / We shall be wholly responsible for any accident or any unusual/ unexpected circumstances
held during the execution of work & also during the CMC period of 5 years.
(Signature of Tenderer)
Date
Name : __________________________
Designation : _____________________
Place :
Seal :
- 36 -
ANNEXURE – IV
COMPANY PROFILE WITH STAFF DETAILS & WORK EXPERIENCE
(To be typed separately & submitted in Envelope No.2)
A} Information :
Name of Company :
Address of Head Office :
Contact Person :
Telephone :
Telefax :
E-Mail :
No. of Branches (Dealers) and their address
Address for Correspondence :
Contact Person :
Telephone :
Telefax :
E-mail :
B} Business Organization : (Please tick wherever applicable & attach all
supporting documents)
Sole proprietorship
Private Limited
Public Sector Undertaking
Limited Company
Joint Venture
C} Business Management : Attach Corporate Organization Chart with Name
D} Total Number of Employees Employed :
1) At Head Office
2) At Branch Office
3) At Site
E} Is Your Organization a Subsidiary of Another Company?
If Yes, of whom?
F} Financial Capability :
Annual Turnover Last 3 Years: Attach Balance sheets of last 3 years. Rs.
Projected this year
Last year
One year before last year
Two year before last year
Three year before last year
Four year before last year
Name and address of the bankers with Contact person and contact numbers.
G} Whether your company hold following certificates:
ISO 9001-2000
OHSAS – 18001-1999
If No, do you substantiate a need to have them
H} Are there any Litigations/ Court cases against your company?
If yes, give details :
I} Any other information that you want to give (may attach separate
- 37 -
Yes/No
Yes/No
Yes/ No
Yes/ No
STAFF DETAILS
Name of the Organization :
List of staff having relevant work experience :
Sl. No.
Name of the Staff
Qualification
- 38 -
Designation
Total
Experienc
e
WORK EXPERIENCE
Name of the Organization :
List of works completed in last 3 years :
Sl. No. Name of the Project Name and address of Contact
Major Items Value of the Start Date
the Client
telephone no’s of the Work work in Rs.
of the Client
/-
Due Date of
Completion
Note : 1. If Actual completion date is beyond the Schedule completion Date, please give reasons for the delay.
Note : 2. Attach relevant completion certificates document for works in previous 3 years.
Authorized Signatory
Company Seal
Date :
Place :
- 39 -
Actual
completion
Date
ANNEXURE- V
TECHNICAL BID
NAME OF WORK: “Design, Supply, Installation, Testing and Commissioning of Two
numbers of each 25 kWp Solar Photovoltaic Power Plants with
aggregated capacity of 50 kWp with Five Years of Operation &
Maintenance Contract”
We confirm the following technical specification.
Sl. No.
1
Item Description
SPV modules for a total capacity of 25 KWp as per
specifications.
a. Capacity
b. Make
c. Module
d. No. of SPV Modules
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
SPV module roof top mounting structure suitable for
accommodating 25 KW capacity SPV modules including
foundation as per specifications on rooftop
PCUs as per specifications
Array Junction Boxes
Main Junction Boxes
Data Logging system with remote monitoring as per
specification
DC Distribution units as per specifications
AC Distribution units as per specifications
Fire extinguisher in accordance with BIS codes for electrical
short circuit fires along with sand buckets
Lightning arrester complete set as per specification
Earthing complete set as per specification
Spares, tools and plant for 5 years operation and
maintenance
Fuses, Transfer switches, Printed Circuit boards required for
power plant
Providing training to engineers and site staff for operating
Maintenance and trouble shooting skills
Operation and Maintenance of Solar Power Plant for a
period of 5 years from date of commissioning of the power
plant.
Any other equipment required to complete the installation
Solar Charge Controller
- 40 -
Item Description
19
20
Power Conditioning Unit
(As per design specification given in tender which includes
charge controller, inverter & Grid charger. The output power
should be on 3 Phase)
Cabling with casing capping
21
Transmission, Distribution & point writing
22
Monitoring, Control & protection device
23
Energy meter (tested by authorized Institute)
24
Metering at generation site
25
Metering at consumption site
26
Control Room
27
Spares ( List of minimum essential spares to be stored by the
Vendor to ensure timely service to RCB units.
28
29
Signature of the Bidder with seal
- 41 -
ANNEXURE- VI
FINANCIAL BID
NAME OF WORK: “Design, Supply, Installation, Testing and Commissioning of Two
numbers of each 25 kWp Solar Photovoltaic Power Plants with
aggregated capacity of 125 kWp with Five Years of Operation &
Maintenance Contract”
The cost of SPV power plant shall includes SPV Power Plant including complete set up in the
control room, cost wiring, switches, MCBs, fuse, etc. as per their respective technical
specification. The cost details for Two SPV power plants with aggregate capacity of 50 kWp
should be submitted as follows:
Sl. No.
Name of the Work
1
“Design, Supply, Installation,
Testing and Commissioning of
Two numbers of each 25 kWp
Solar Photovoltaic Power Plants
with aggregated capacity of 50
kWp with Five Years of
Operation
&
Maintenance
Contract”
(as per site conditions) As per
tender Document
Capacity
(i) RCB Building
25 kW
(ii) THSTI Building
25 kW
Total cost
Cost of SPV Power Plant
including complete set up in the
control room [A] (Cost of
Material + Cost of installation and
commissioning, testing at the
site) + Cost of CMC with 5 yrs. [B]
+ Cost of providing manpower for
same [C]
quote separately as
[A ] + [B] + [C]
50 kW
Rupees (in words) ……………………………………………………………….
Signature of the Bidder with seal
- 42 -
ANNEXURE- VII
Accredited Test centers for MNRE Online Grid Programme
Lab/
Organization
SEC
ERTL
(east)
ETDC
(B)
CPRI
(B)
PV Module
Yes
(IEC 61215 up to
100 Wp)
NABL Accredited
STC Test Facility
MNRE Accredited
Yes
(IEC61215) under
ICEEE-CB, IEC
61701 (up to 100
Wp) NABL
Accredited
No
Lighting Systems
As per MNRE
specifications
Yes
MNRE
Accredited
Inverter > 100 W
Charge controller
Environmental
Efficiency
Environmental
Protections
Environmental
Yes
(up to 10 kVA)
MNRE Accredited
Yes
(including IP)
MNRE
Accredited
Yes
NABL/ MNRE
Accredited
Yes
NABL/ MNRE
Accredited
Yes
MNRE
Accredited
Yes
NABL/ MNRE
Accredited
Yes
NABL/ MNRE
Accredited
Yes
(including IP)
MNRE
Accredited
Yes
NABL/ MNRE
Accredited
Yes
NABL/ MNRE
Accredited
Yes
NABL/ MNRE
Accredited
Yes
NABL/ MNRE
Accredited
Yes
(including IP)
MNRE
Accredited
Yes
NABL/ MNRE
Accredited
Yes
NABL/ MNRE
Accredited
Yes
NABL/ MNRE
Accredited
Yes
NABL/ MNRE
Accredited
Yes
(up to 10 kVA)
NABL/ MNRE
Accredited
Yes
(up to 5 kVA)
NABL
Accredited
Yes
(up to 6 kVA)
NABL
Accredited
Yes
NABL/ MNRE
Accredited
Yes
NABL/ MNRE
Accredited
Yes
NABL/ MNRE
Accredited
Yes
NABL
Accredited
Yes
(up to 5 kW)
NABL
Accredited
Yes
(up to 6 kW)
NABL
Accredited
Yes
NABL
Accredited
ERTL
(N)
No
Only Electronics
& luminaire NABL
Accredited
Yes
NABL
Accredited
UL (B)
Yes
(IEC61215) IEC
61730
Pt.II and IEC 61701
(up to 400 Wp)
NABL Accredited
Yes
(except battery)
NABL
Accredited
Yes
NABL
Accredited
Yes
NABL/MNRE
Accredited
Yes
(up to 3 kVA)
NABL/ MNRE
Accredited
- 43 -
Yes
NABL
Accredited
Yes
NABL
Accredited
TUV
Rhineland
Inter Tek
Yes
(IEC61215) & IEC
61730
Pt.II
(up to 400 Wp)
NABL Accredited
No
No
Yes
NABL
Accredited
Yes
(up to 10 kVA)
NABL
Accredited
Yes
NABL
Accredited
Yes
(up to 10 kW)
NABL
Accredited
Yes
NABL
Accredited
Only Electronics
& luminaire NABL
Accredited
Yes
NABL
Accredited
Yes
(up to 5 kVA)
NABL
Accredited
Yes
NABL
Accredited
Yes
(up to 5 kW)
NABL
Accredited
Yes
NABL
Accredited
- 44 -
CHECK LIST
Documents to be submitted in Envelope No : 1
1. PV module test certifications IEC 61215/ IEC 61730/ IEC 61731/ IEC 61732
2. Chanel partner certification
3. Experience proof of MNRE allocation of 250 kWp & above
4. Proof of business certificate of minimum 7 years
5. A grade electrical license certification
6. ISO 9001-2008 or 14001 2004 certification
7. Govt. experience if any
If any of the documents is not submitted in envelope 1, the tender will be rejected.
Documents to be submitted in Envelope No : 2.
1.
Original tender document duly signed and stamped on each page _____
2.
3.
Details of Earnest Money Deposit as format given in tender document at _____
Earnest Money Deposit (EMD) refer page 4 Annexure-I
Name of authorized person (power of attorney) for submitting the document.
4.
Name of the Banker if any
5.
Undertaking/Declaration on Rs. 100/- stamp paper refers Annexure-III.
6.
Copy of latest copy of income Tax returns, PAN number, registration under VAT, VAT
clearance certificate, ref page no 6.
7.
Information on Infrastructure for maintenance work
8.
General Information of the firm refer Annexure II.
9.
Profile, Staff Details and Experience Annexure IV.
10.
P & L, Balance sheets or certificate from CA for indicating the turnover of during last 3
years.
11.
Experience Certificate showing stipulated work of at least one crore
12.
Copies of the satisfactory commissioning reports for SPV power plants of total minimum
250kW capacity duly signed by the user.
13.
Detail drawings of mounting structure Solar PV power plant and other structures like
control room etc.
14.
All other documents as per the tender document.
15.
Technical bid details as per Annexure V.
If any of the documents is not submitted in envelope 2, the tender will be rejected.
Document to be submitted in ENVELOPE No -3
1. Financial bid/ offer in prescribed format for system / systems tendered refers Annexure- VI
2. Detailed work-wise / item-wise break –up
Document to be submitted in ENVELOPE No:-4
Cost of tender document if tender document is downloaded from website.
Note:- Tenderer should submit the complete tender document and other required documents to be
attached as per the list mentioned and in the order
- 45 -
Was this manual useful for you? yes no
Thank you for your participation!

* Your assessment is very important for improving the work of artificial intelligence, which forms the content of this project

Download PDF

advertising